SOLAR TERMS AND CONDITIONS

Agreement

This Agreement and/or the Order Form govern the supply of Solar PV (the products) and installation of same by CYANERGY to the Customer named in the schedule.
The Agreement is governed by the laws of the Australian States and Territories in which the Premises are located, and each party irrevocably submits to the non-exclusive jurisdiction of the courts. The customer’s rights under the warranty sit alongside the customer guarantees which are required under ACL and cannot be excluded.
By entering into this Agreement with you, we agree to comply with the Clean Energy Council’s Code of Conduct.
In the interpretation of this Agreement, unless the contrary intention appears:
- headings are for convenience only and do not affect the interpretation of this Agreement;
- the words “includes” or “including” will not limit whatever follows;
- a reference to a person includes a reference to a corporation, firm, association, or other entity, and vice versa; the singular includes the plural and vice versa; a reference to any gender includes a reference to all other genders;
- a reference to any legislation includes a reference to any modification or re-enactment of that legislation; and
- where an expression is defined, another part of speech or grammatical form of that expression has a corresponding meaning.

Orders

5.Each Order constitutes an offer by the Customer to CYANERGY to purchase Solar PV and the Installation of the Solar PV and is subject to acceptance by CYANERGY. Any Order accepted by CYANERGY shall constitute a binding agreement between the Customer and CYANERGY on the terms of this Agreement.

6.If a site-specific full system design is not provided with the contract, it will be a deliverable of the contract and

this information will be provided before the expiry of the cooling-off period; and
the consumer is entitled to a full refund upon request, if s/he do not consent to the site-specific full system design and performance estimate upon receipt of this information.

Cooling OFF Period

7.Customer can cancel the order within 10 business days cooling off period.

8.No installation will take place during this cooling off period.

9.If the customer wants to cancel after this cooling off period, the initial deposit will be forfeited unless it is covered under ADDITIONAL EXPANSES or REFUND terms.

Variation Or Cancellation By Customer

10.The Customer shall not vary or cancel an order, or change the Installation Date, without the written consent of CYANERGY.

11.If CYANERGY does elect to accept variations to the Order, the Customer shall pay for any variations to the Order at rates specified by CYANERGY which shall be in addition to the Price.

12.In case of any variation from the original, CYANERGY and customer both need to sign a variation contract.

13.The Customer may, however, by written notice to CYANERGY, cancel an order for the Products prior to installation:

under the circumstances agreed mutually; or
if the Products are not installed within 6 months of the customer placing an order

14.If the Customer cancels an order for the Products, then subject to the Customer having complied with its obligations under this Agreement, CYANERGY will provide a full refund to the Customer of all amounts paid prior to cancellation.

15.CYANERGY may at its sole and absolute discretion, by written notice to the Customer, cancel an order and/or terminate this Agreement at any time prior to installation of the Products, and for any reason whatsoever.

16.Upon such termination, and subject to the Customer having complied with its obligations under this Agreement, CYANERGY will pay a full refund to the Customer of amounts paid prior to such cancellation or termination.

Availability Of Products

17.If the original Products, ordered by the Customer, are not available at the time of installation, the customer agrees that CYANERGY may substitute an item or component of equivalent or better specifications to the Component that the customer originally purchased. In such instances, CYANERGY will inform the customer prior to the installation date and request for an approval in writing beforehand. If the customer does not agree with the proposed substitution, CYANERGY will reschedule the installation with the original products or delivery of the original products when they are available.

18.CYANERGY shall not be liable to the Customer to make good any loss or damage whether arising directly or indirectly as a result of any ensuing delay in delivery that is properly communicated.

Payment

19.All prices charged by CYANERGY are subject to change with prior notice and unless otherwise specified, are exclusive of any GST. CYANERGY price lists or price catalogues do not constitute an offer by CYANERGY to supply any item set out in the price lists or price catalogues at the listed price.

20.Unless the Customer has been approved for Credit in writing by a finance company the Customer must pay to CYANERGY:

the 10% Deposit, upon receiving the full proposal document and System Performance Estimate (SPE)
the Balance due on installation completed or specified in the payment schedule;

21.All payments by the Customer are to be made in cash, Credit Cards, bank cheque or other cleared funds.

22.The Customer must also pay to CYANERGY at the same time the Price is payable GST, and all other applicable taxes, duties, levies, penalties and any other government charges payable in relation to the supply of Products or provision of Services (which have not been included in the Price) on demand by CYANERGY.

23.If the Customer defaults in the payment of any sum of money due to CYANERGY, CYANERGY may charge interest at the current Victorian Penalty Rate calculated daily until the date of payment and CYANERGY may cancel any Orders in existence (without prejudice to any other rights or remedies of CYANERGY).

24.The Customer must make all payments to CYANERGY required by this Agreement without set-off, deduction or counterclaim, and the customer agrees that the interest rate nominated is in the circumstances fair and reasonable.

25.If the payment is not paid within 10 business days after installation, CYANERGY keeps the right to pass the debt to a debt recovery agency and customer is liable for any additional changes from the debt recovery agency.

GST Explain

26.If the customer assigns the right to create the STCs on the installation of eligible system, it is regarded as a sale for GST purposes.

27.If the customer is not registered or required to be registered for GST, then the assignment will not be subject to GST.

28.Where the assignment leads to price offsetting, the GST consequences of purchasing the system and assigning the STCs need to be considered separately.

Credit / Cyanergy Finance Supplier

29.If the Customer has been approved for Credit, payment must be made to CYANERGY within 10 days of invoice, or another such period, if any, as agreed in writing by CYANERGY

Approval To Connect To The Electricity Grid

30.The customer is advised (where relevant in the state of installation), before a contract is signed, that:

the customer requires approval from their distributor to connect a solar PV system to the electricity grid (“grid connection approval”); and
the relevant paperwork must be completed and submitted prior to installation.

31.The scenario where customer takes responsibility for obtaining grid connection approval and the application is rejected where the contract has already been signed, the customer is entitled to the return of all moneys paid minus reasonable expenses incurred by CYANERGY to the point of termination of the contract.

32.In case the customer authorises CYANERGY to prepare and submit the documentation required for grid connection approval and the application is rejected where the contract has already been signed, the customer is entitled to a full refund.

Installation Date

33.CYANERGY will endeavour to arrange the Installation:

If you are within a 50 kms radius from the GPO in an Australian Capital City or Major Metro Area – within 4 to 6 weeks, following notification of grid connection approval; or
if you are in any other area – within 8 to 12 weeks, following notification of grid connection approval.
battery installations may take up to 12 weeks for all areas, following notification of grid connection approval.

34.The Customer acknowledges that the Installation Date is an estimate only and should CYANERGY be unable to install the Products by the Installation Date due to unforeseen circumstances outside of our control then:

The Installation date shall be extended by any reasonable amount of time deemed necessary by CYANERGY and the customer will be notified as soon as the changed scenario is determined; and/or
CYANERGY may at its sole discretion cancel any Order, in which case any amounts paid to CYANERGY by the Customer shall be refunded.

Installation

35.Installation will be conducted by our “CEC” accredited installer.

36.If any brand is not available or shortages in market will delay installation and the customer will be notified in written.

37.Any product CYANERGY cannot install but the customer already charged for, will be refunded.

38.If the original order form is overquoted or underquoted, will be adjusted by signing a variation contract prior installation.

Small-Scale-Technology Certificate (STC) And Tariff Rates

39.Upon entering into this Agreement to install Solar PV, the Customer unconditionally undertakes to assign and is deemed to have assigned to CYANERGY its right to claim Small-scale technology certificates (STCs).

40.The Customer agrees to complete and execute for the benefit of CYANERGY any documents, contracts, or papers reasonably necessary to give effect to this assignment. The Customer undertakes not to otherwise deal with its right to claim Small-scale technology certificates (STCs). After completion of the installation, the customer shall be present & sign the documentation at the request of the installer.

41.CYANERGY will not be liable for the value of any Feed in Tariffs (FiT’s), incentives such as Small-Scale Technology Certificates (STC’s), any government rebates etc.

42.The electricity contract/tariff may change following installation of solar and that the customer should contact their electricity retailer: before signing a contract, to check what new electricity tariff rates may be applied; and after installation of the solar PV system, to confirm that the agreed tariff has been applied.

Solar VIC Rebate And Interest Free Loan

43.It is customers responsibility to apply for the Victorian state government solar rebate and interest free loan.

44.Any pricing offered by CYANERGY which includes the Victorian state government rebate is subject to approval by Solar Victoria.

45.CYANERGY reserves the right to rescind this contract should approval be declined by solar Victoria. For further information please visit solar.vic.gov.au

Provision Of The Services

46.CYANERGY shall use its best endeavours to provide the Services by the Installation Date.

47.Unless otherwise agreed by the parties in writing, CYANERGY shall not be responsible for providing any services other than the Services (including any variations to the Services).

48.The Customer grants permission to CYANERGY and its employees, contractors and/or agents to enter, at any time, the premises at the Installation Address, for the purposes of performing the Services.

49.The Customer agrees to make himself/ herself or a representative present at the premises, when and as reasonably required by CYANERGY or its employees, agents and contractors.

Force Majeure Event

50.If CYANERGY becomes unable, due to the occurrence of a Force Majeure Event, to carry out any obligation, in whole or in part, placed on it by this Agreement, CYANERGY may, in its absolute discretion either:

Suspend performance of that obligation, so far as it is affected by the Force Majeure Event, during the period the Force Majeure Event continues; or
Cancel the Customer’s Order without liability.

Additional Expenses

51.The Customer may be liable to pay Additional Expenses, not covered in the Quote, in connection with the Products or Services if CYANERGY or it’s contractors deem that the Customer’s premises are not immediately suitable for the installation due to site conditions or special circumstances.

52.Additional Expenses anticipated by CYANERGY at the Order Date shall be itemised in the order form. However, these expenses are estimates only and are not binding on CYANERGY.

53.If CYANERGY determines that the Customer is required to pay any Additional Expenses not provided for in the order form, in order to complete the services, CYANERGY will first notify the Customer of the quantum of the Additional Expenses and give the Customer an option to sign the variation contract. In such instances, customer can choose to cancel or terminate contract at their discretion to get full refund.

54.If the customer doesn’t accept the variation contract, CYANERGY will complete the job in the original contract whatever possible without any additional cost.

Refund

55.If any significant changes to the design of the PV system, including the estimated performance is determined during/prior installation, CYANERGY will seek customer’s approval through a fresh quote or variation contract; otherwise the customer shall be refunded in full.

56.The customer will get a full refund upon request when:

the final system design provided is significantly different to that quoted at the point of contract and is not signed off by the customer;
the site-specific full system design and performance estimate is provided as a deliverable of the contract and:
1. this information is not provided before the expiry of any cooling- oﬀ period; and
2. the customer does not consent to this information upon receiving it;
the estimated delivery timeframe for installation completion that was agreed upon at the point of contract is not honoured, for reasons reasonably within the CYANERGY’s control, and the customer does not consent to a revised timeframe;
if CYANERGY acting on behalf of the customer to obtain grid connection approval does not do so prior to installation, and the customer does not receive approval from the distributor to connect a system; and
extra chargeable work arises, which was not specified in the initial contract, and the additional costs are not borne by the Signatory and the customer does not consent to these additional costs.

Title To The Products

57.The Products remain the property of CYANERGY (and CYANERGY retains title to the Products) until the Price and any other payment or sum due to CYANERGY has been paid in full by the Customer, regardless of whether installed or not and regardless of the location of goods.

58.All Products shall be at the risk of the Customer from the time that installation of the Products at the Customer’s premises has been completed.

59.The Customer must not offer, sell, assign, sublet, mortgage, pledge, Encumber or otherwise deal with the Products in any way which is inconsistent with or would detract from CYANERGY’s ownership of the Products until the Price and any other payment or sum due to CYANERGY has been paid in full by the Customer. If requested by CYANERGY, the Customer must ensure the Products are clearly identifiable as the property of CYANERGY.

60.In the event that the Customer is in default of its obligations under this Agreement, any Order or any other agreement that exists between the Customer and CYANERGY, CYANERGY will at its election be entitled to the immediate return of the Products and for this purpose may enter the Customer’s premises to recover any Products. If CYANERGY so elects, the Customer must at its cost take all necessary action (including obtaining the consent of any third party) to enable CYANERGY to exercise its rights under this clause.

Discrepancy Of Products

61.Unless otherwise stated by CYANERGY in writing, the exact specifications, dimensions, and masses quoted in respect of any Products are approximate and subject to change without notice and subject to commercial tolerances.

62.The Customer affirms for the benefit of CYANERGY that any and all information provided by the Customer to CYANERGY in connection with any Order to purchase the Products is true and correct.

Privacy/Credit Reporting

63.The Customer agrees to sign any consents or other forms required by CYANERGY under which it will consent, amongst other things, to CYANERGY obtaining credit information about the Customer or providing a credit report in relation to the Customer or exchanging credit information about the Customer to third parties.

Intellectual Property

64.The Customer acknowledges and agrees that under no circumstances will it take any interest in CYANERGY’s Intellectual Property, and CYANERGY reserves all of its rights in respect of its Intellectual Property.

Default

65.Upon the occurrence of an Event of Default, CYANERGY may by notice in writing to the Customer:

elect that all monies owing by the Customer to CYANERGY under this Agreement, any Order or any other agreement that exists between the Customer and CYANERGY (including but not limited to any Credit) whatsoever become immediately due and payable in full by the Customer; and/or
terminate an Order, or all Orders with the Customer.

66.In respect of any terminated Order (other than an Order validly cancelled by the customer under the terms of this agreement) the Customer must pay to CYANERGY any and all losses, damages, costs, interest, fees, charges (including handling charges) and expenses incurred or suffered by CYANERGY and its suppliers as a result of the Customer’s default of this Agreement and the subsequent cancellation of the Order. The Customer shall have no recourse whatsoever against CYANERGY as a result of any termination of an Order by CYANERGY under this agreement.

67.The Customer must give CYANERGY full details of any Event of Default as soon as it becomes aware that an Event of Default has occurred.

68.Each of these events or circumstances is an Event of Default:

the Customer fails to comply with this Agreement or the terms of any contract or Order between the Customer and CYANERGY;
the Customer being an individual is declared bankrupt or becomes of unsound mind;
the Customer enters into any composition or arrangement with its creditors or goes into liquidation (voluntarily or otherwise) or has a receiver or liquidator or trustee or administrator or similar official appointed over all or part of its assets;
the Customer ceases or CYANERGY ceases to carry on all, or substantially all, of its business or operations;
an order being made, or the Customer passing a resolution, or any other step is taken, for the Customer’s winding up (including but not limited to an application being made to a court for an order for its winding up);
the Customer becomes or is declared or is deemed to be insolvent, or is unable or deemed to be unable to pay its debts, generally;
the Customer undergoes a change in its control or ownership not approved by CYANERGY in writing; or
an event or circumstance occurs in relation to the Customer which is analogous to any event or circumstance specified in paragraphs (b) to (f).

Liability/Indemnity

69.The parties acknowledge that, under applicable State and Commonwealth law, certain clauses, conditions, guarantees and warranties may be implied in this Agreement and there are rights and remedies conferred on the Customer in relation to the provision of goods or of services which cannot be excluded, restricted or modified by agreement (Non-excludable Rights). The terms of this Agreement are subject to the non-excludable rights.

70.Except to the extent of Non-Excludable Rights, CYANERGY will not be liable for:

any claim by the Customer or any other person, including without limitation, any claim relating to or arising from all clauses, conditions, guarantees and warranties expressed or implied, and all rights and remedies conferred on the Customer, by statute, the common law, equity, trade, custom or usage or otherwise; and
any representations, warranties, conditions or agreement made by any agent or representative which are not expressly confirmed by CYANERGY in writing and the liability of CYANERGY for any such matters is hereby excluded.

71.Where (and to the extent) permitted by law the liability of CYANERGY of a Non-Excludable Right can be limited, CYANERGY’s liability is limited, at CYANERGY’s election, to one of the following:

replacement of the Products or supply of equivalent products;
resupply of the affected Services;
repair of the Products;
payment of the costs of replacing the Products or acquiring equivalent products;
payment of the cost of providing equivalent services to the affected Services; or
payment of the cost of having the Products repaired.

72.Notwithstanding any other provision in this Agreement, CYANERGY is in no circumstance (whatever the cause) liable in contract, tort (including, without limitation, negligence or of statutory duty) or otherwise to compensate the Customer for any:

costs or expenses;
loss of profit, revenue, business, contracts or anticipated savings;
loss or expense resulting from a claim by a third party;
special, indirect or consequential loss, damage or expense; or
death or personal injury, whatsoever and howsoever arising.

73.To the full extent permitted by law, CYANERGY’s liability to the Customer for all claims made by the Customer, in relation to an of this Agreement or otherwise, whether arising under contract, negligence or any other tort, under statute or otherwise, will not exceed in aggregate the amounts paid by the Customer under this Agreement.

General

74.This Agreement contains the entire agreement between the parties about its subject matter. Any previous understanding, agreement, representation or warranty relating to that subject matter is replaced by this Agreement and has no further effect.

75.This Agreement may only be varied by written agreement between the parties.

76.The rights of CYANERGY are cumulative and are in addition to any other rights of that party.

77.This Agreement is governed by the laws of the Government of Australia and the parties irrevocably submit to the non-exclusive jurisdiction of the courts.

78.Any provision of this Agreement which is unenforceable, illegal or void or partly unenforceable, illegal or void is, where possible, to be severed to the extent necessary to make this Agreement enforceable, but so as not to affect the enforceability of the remaining provisions of this Agreement.

79.No failure or partial failure by a party to enforce any of its rights under this Agreement constitutes a waiver or partial waiver of that right, and no waiver is effective unless it is in writing and signed by authorised representatives of each party.

80.The Customer shall not assign its rights, or novate is obligations, under this Agreement without the prior written consent of CYANERGY. CYANERGY may assign its rights or novate its obligations under this Agreement, without obtaining the consent of the Customer.

81.The customer gives permission for pictures to be taken before, during, and after install. These pictures are the property of CYANERGY. And, the pictures along with installation summary may be used in various marketing contents.

82.The Customer must promptly sign all documents and do all things that CYANERGY from time to time CYANERGY reasonably requests to effect, perfect or complete this Agreement and all transactions incidental to it.

83.Any notice that is required to be given under this Agreement must be in writing. It may be:

hand delivered – in which case the notice will be deemed to have been received once it has been delivered;
transmitted by facsimile if the recipient has facilities for the transmission of documents by facsimile – in which case the notice will be deemed to have been given at 9:00am on the next day following the date of transmission; or
mailed by prepaid post – in which case the notice will be deemed to have been given at 5:00pm on the third day following the date of posting. to the last known address or facsimile number of the recipient.
email to the customer email address – in which case the notice will be deemed to have been given at 9:00am on the next day following the date of transmission.

84.Customer acknowledges that CYANERGY has made no representation in relation to the continuity of feed-in tariffs or the quantum or rate thereof the customers further acknowledge is that he/she they have made their own enquiry into the performance of the solar system.

85.The customer acknowledges in the event that CYANERGY or its installers are unable to install the Solar system by reason of the condition of the premises not complying with the requirement of any governmental or statutory body, or if the premises are deemed to be too unsafe for the purpose of the installation by CYANERGY or its sub-contractors then CYANERGY may terminate this agreement.

86.In the event that any claim is made by you as the customer under any warranty agreement or obligation provided by the manufacturer of the goods supplied and such claim is made after the expiration of warranty from the date of installation of such good which requires CYANERGY or its sub-contractor to attend at the installation address then CYANERGY will be entitled to charge a fee, commiserate with the cost of the provision of that service.

87.The customer acknowledges that the Goods are the subject of a warranty produced by the manufacturer and that in no circumstances shall CYANERGY be liable should the warranty become for any reason unenforceable beyond CYANERGY’s minimum 5 year whole of system warranty on the operation and performance of the system, including workmanship and products .

88.In the event during the course of installation any damage to the roof tiles or other roofing materials, CYANERGY accept no liability for replacement of damaged tiles or any other roofing materials.

5 Performance Guarantee Terms and Conditions

Subject to the terms of this Guarantee including clause 7 of
this Agreement and otherwise in addition to all rights and remedies to which
you may be entitled to under the ACL or any other applicable law:

5.1 The Company guarantees for the Guarantee Period, that
the Goods as installed by the Company will have an annual system production of
kWh determined using the following formula: ((Nearest city average daily
production from PV-GC CEC GC Design Guidelines x Solar system size (AC kWp) x
No. of days in the Relevant 12 Month Period) x 90%) (referred to as Guaranteed
Generation).

5.2 The determination as to whether clause 5.1 of this
Agreement has been satisfied will be assessed at the end of the Relevant 12
Month Period by the Company determining the Actual Generation by the Goods
during the Relevant 12 Month Period using the Inverter Meter (Actual
Generation).

5.3 For the avoidance of doubt, in determining whether the
Guaranteed Generation has been satisfied in the Relevant 12 Month Period, the
determination of the Actual Generation is based on the kW production of the
Goods during the Relevant 12 Month Period and it is acknowledged at during the
Relevant 12 Month Period there may be times where:

5.3.1 the kW production of the Goods is less than the
Guaranteed Generation; and

5.3.2 the kW production of the Goods is more than the
Guaranteed Generation.

5.4 If in the Relevant 12 Month Period the Actual Generation
of the Goods as installed by the Company is less than the Guaranteed
Generation, the Company will pay to the End User, and the End User acknowledges
and agrees that the liability of the Company is limited to, an amount
determined using the following formula (referred to as the Guarantee Payment):
(Guaranteed Generation – Actual Generation) ! Effective Solar Rate Where,
Actual Generation means the actual kWh generation by the Goods during the Relevant
12 Month Period and as determined by the Company using the Inverter Meter.

5.5 If any time the Company is liable to pay to the End User
the Guarantee Payment, the Company will pay this amount in accordance with
clause 8 of this Agreement.

5.6 Events that could limit the Actual Generation of the
Goods and to which the Guarantee will not apply, include but are not limited
to:

5.6.1 electricity shutdown at the Site; 5.6.2 electricity
re-configuration at the Site;

5.6.3 lack of access to the Grid (be it intentional or
unintentional); and

5.6.4 failure of the Grid.

6 Inverter Meter And Report

6.1 The End User acknowledges that there is an Inverter
Meter installed on the Goods which electronically reports to the Company the kW
production of the Goods.

6.2 The End User acknowledges and agrees that the usage
readings obtained by the Company from the Inverted Meter will be binding on the
End User.

6.3 The End User acknowledges and agrees that the Company
(or its nominees, agents or sub-contractors) may from time to time require
access to the Inverter Meter for readings and Maintenance.

6.4 The End User acknowledges that it will not refuse any
reasonable request by the Company to attend the Site in order to conduct
readings or perform Maintenance on the Inverter Meter.

6.5 Within 60 days of the expiration of the Relevant 12
Month Period, the Company will provide to the End User a report detailing the
Actual Generation for that Relevant 12 Month Period and if there is any
Guaranteed Payment payable under clause 5.4 of this Agreement, the calculation
of the amount of that Guaranteed Payment (Report).

7 Conditions Of Guarantee

7.1 The Guarantee only applies to the End User and is only
transferable under the consent of the Company which may be withheld at its
absolute discretion.

7.2 The Guarantee and any obligation of the Company to pay
the Guarantee Payment will not apply where:

7.2.1 there have been any maintenance services,
modifications, repairs or alterations, and which for the avoidance of doubt
includes cleaning, to the Goods (including the Inverter Meter) not performed by
the Company;

7.2.2 there has been inadequate Maintenance of the Goods,
failure to repair or otherwise failure to comply with the Company’s recommended
Maintenance of the Goods or the manufacturer’s instructions;

7.2.3 the Goods as installed do not have exposure to
sunlight in accordance with the Site Map provided by the Company;

7.2.4 there is a variation to or failure to comply with the
Site Map;

7.2.5 access is not provided at the Site for the performance
of the Services when the Company or its agents or subcontractors attends to
inspect or otherwise undertake repairs to the Goods;

7.2.6 save for as a result of an act or neglect of the
Company, the Goods have been damaged in any way;

7.2.7 there is a Force Majeure Event such that clause 10 of
this Agreement applies;

7.2.8 the End User has failed to comply with any provision
of this Agreement;

7.2.9 the End User is otherwise in breach of any provision
of this Agreement or otherwise there is a Default Event;

7.2.10 there has been substantial changes to the environment
surrounding the Site causing any shading of the Goods, including but not
limited to:

7.2.10.1 new construction works; and

7.2.10.2 tree growth.

7.3 For the avoidance of doubt the Guarantee is provided in
respect to the electricity generated by the Goods and not the ability for the
generated electricity to be consumed by the End User. Examples of events that
could limit the consumption of electricity generated by the Goods by the End
User and to which the Guarantee will not apply, include but are not limited to:

7.3.1 electricity shutdown at the Site;

7.3.2 electricity
re-configuration at the Site;

7.3.3 lack of access to the Grid (be it intentional or
unintentional); and

7.3.4 failure of the Grid.

7.4 Notice of damage The End User must as soon as reasonably
practicable provide notice to the Company of any damage to the Goods.

7.5 Reasonable Access

7.5.1 The Company requires adequate access to the Goods to
inspect the Goods and the condition of same.

7.5.2 The End User must permit the Company, its agents or
subcontractors to enter the Site during normal business hours, after giving
reasonable notice (except in the case of emergency):

7.5.2.1 inspect the Goods; or

7.5.2.2 to carry out repairs or maintenance to the Goods.

7.5.3 If access to the Site is not available when the
Company or its agents or subcontractors attends to inspect or otherwise
undertake repairs to the Goods, the End User will be in breach of this
Agreement. 8 Payment Of Any Guaranteed Payment If a Guaranteed Payment is
payable By the Company to the End User in accordance with clause 5.4 of this
Agreement, the Company will pay the Guaranteed Payment to the End User within
30 days of providing the Report.